Interior Works Terms and Conditions
1. Scope of Work:
- The scope of work includes all interior design and construction services as agreed upon between the client and [Your Company Name]. This encompasses but is not limited to design concepts, space planning, material selection, procurement, installation, and project management.
2. Client Responsibilities:
- The client agrees to provide accurate and timely information necessary for the completion of the project.
- The client will promptly respond to any queries or requests for approval from [Your Company Name] to avoid delays in the project timeline.
- Any changes or modifications requested by the client after the commencement of work may result in additional charges and/or adjustments to the project timeline.
3. Payments:
- A deposit of [Percentage]% of the total project cost is due upon signing this agreement. The remaining balance shall be paid according to the payment schedule outlined in the agreement.
- Payment milestones are tied to specific stages of the project and are non-negotiable unless otherwise agreed upon in writing by both parties.
- Failure to make payments according to the agreed-upon schedule may result in the suspension of work until payment is received.
4. Project Timeline:
- [Your Company Name] will make every effort to adhere to the project timeline agreed upon with the client. However, unforeseen circumstances such as weather delays, material shortages, or other factors beyond our control may affect the timeline. In such cases, [Your Company Name] will communicate promptly with the client to discuss revised timelines.
5. Changes and Revisions:
- Any changes or revisions to the project scope requested by the client must be submitted in writing and may result in additional costs and/or adjustments to the project timeline.
- [Your Company Name] reserves the right to refuse any requested changes or revisions that are deemed impractical or outside the scope of the original agreement.
6. Warranty:
- [Your Company Name] warrants that all materials used and work performed will be of professional quality and free from defects.
- Any defects or issues arising from the work performed by [Your Company Name] will be rectified at no additional cost to the client within a reasonable period after notification.
7. Termination:
- Either party may terminate this agreement with written notice if the other party fails to fulfill its obligations under this agreement.
- In the event of termination, the client agrees to pay for all services rendered and expenses incurred by [Your Company Name] up to the date of termination.
8. Confidentiality:
- [Your Company Name] agrees to maintain the confidentiality of any proprietary or sensitive information disclosed by the client during the course of the project.
9. Governing Law:
- This agreement shall be governed by and construed in accordance with the laws of [Your Jurisdiction], and any disputes arising under this agreement shall be resolved exclusively in the courts of [Your Jurisdiction].
10. Entire Agreement:
- This agreement constitutes the entire understanding between the parties and supersedes all prior agreements and understandings, whether written or oral, relating to the subject matter herein.
11. Acceptance:
- By signing below, the client acknowledges that they have read, understood, and agreed to the terms and conditions outlined in this agreement.
Please note that the above terms and conditions are for reference purposes only and should be reviewed by legal professionals to ensure compliance with local laws and regulations.